英文合同

时间：2024-09-02 04:11:25 合同范本我要投稿

英文合同范文汇总十篇

　　现今社会公众的法律意识不断增强，随时随地，各种场景都有可能使用到合同，签订合同也是避免争端的最好方式之一。那么常见的合同书是什么样的呢？以下是小编为大家收集的英文合同10篇，欢迎阅读与收藏。

英文合同范文汇总十篇

英文合同篇1

　　主合同编号（Contract NO）：

　　买方（Buyer）：

　　地址（Add）：

　　电话（Tel）：传真（Fax）：

　　生产厂（Producer）：

　　地址（Add）：

　　电话（Tel）：传真（Fax）：020-32915578

　　为体现诚实信用的合同履行精神，防止延期交货的.情况出现，双方协商一致，特制定如下条款：

　　In order to reflect the spirit of good faith and for avoidance of any delay in delivery, both parties hereby agree as follows:

　　一、本协议是执行主合同的关于延期交货的特别约定，主合同编号为：。

　　This agreement shall constitute a special covenant for implementing the provisions of delayed delivery as set forth in the Master Contract(Contract No._______).

　　二、主合同约定的交货日期为：年月日，运输方式为海运集装箱。

　　Delivery date provided in the Master Contract shall be _________, and transportation mode is marine container.

　　三、若生产厂无法按照上述交货期限的约定交货的，则买方有权要求改为空运方式运输，相应的空运费用约美元（USD）从买方应当支付给生产厂的货款中扣除。(实际扣除金额以空运费单据为准)

　　Where the Producer fails to deliver goods pursuant to the above delivery period, the Buyer has right to amend the original transportation mode to air transportation and corresponding air freight charge is around _______(USD) deductible from payments for goods made by the Buyer to the Producer. (actual deductible amount shall be subject to air freight receipts)

　　买方（Buyer）：

　　买方代表人：（签章）Representative： (Sgn & Samp)

　　生产厂（Producer）：

　　生产厂代表人：（签章）Representative： (Sgn & Samp)

　　签约时间：年月日

　　Date of Signing：（D-M-Y）

　　注：本合同内容如有中英文翻译误差，以中文为准。

　　Note: If this contract content has any error of translation, subject to Chinese.

英文合同篇2

　　Address:

　　Telephone：

　　Party B: Address:

　　Telephone：

　　According to the provisions of the contract law of the People's Republic of China and the relevant laws and regulations, Party B accepts the entrustment of the first party and entrustment with the two parties through consultation.

　　First, entrustment:

　　Two, the way of payment:

　　1, Party A shall pay 40% of the total cost of the contract, namely ____ yuan (RMB) to Party B, Party B received the money after the start of design.

　　2. Party B shall provide complete design draft. After confirmation by Party A, the total amount of the total cost shall be paid.

　　Three. Design time:

　　1, Party B shall provide complete design draft in __ working days.

　　2, Party B shall complete the design work of party a company commissioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).

　　Four. The responsibilities and obligations of the two parties:

　　1, Party B shall, according to the requirements of Party A to finish the related work on time.

　　2, Party A has the responsibility to fully cooperate with Party B to carry out the work stipulated in this contract and provide relevant information according to the needs of Party B. Party A is responsible for the consequences caused by Party A's delay in the required information.

　　3. Party A shall provide complete design information before the start of the design, due to Party A's provision of incomplete information and changes in content.

　　For structural changes, Party A shall pay the corresponding cost of design changes.

　　4. After Party B receives the complete design information of Party A, it is designed to facilitate the determination of the style of Party A, and Party B begins to design the first draft after the style is determined.

　　5, Party A has the right to put forward amendments to the works designed by Party B. The first draft Party A can make a structural modification. After the first draft is determined, the structural modifications should be made. Party A shall pay the corresponding cost separately.

　　6. The consequences of the delay due to the amendment of Party A shall be borne by Party A.

　　7, due to the loss caused by post production by Party A alone, the loss caused by problems in the design of the product is borne by Party B. The legal liability caused by copyright, for the economic disputes shall be borne by Party a..

　　8. During the course of the project, Party B is attached to the brand of Party A and shall not sign any form of cooperation agreement with the customer in the identity of Party B.

　　Five. The agreement on intellectual property rights:

　　1, Party B has the copyright of the works completed by the design. After the settlement of all the fees designed by Party A, Party B may transfer the copyright of the works to Party A.

　　2. Before Party A has not paid all the cost of the design, the copyright of the works designed by Party B shall be attributed to Party B, and Party A does not have any right to the work.

　　3. Party A shall have the right to investigate the legal liability of Party A if it uses or amends the works designed by Party B before the payment is not paid.

　　Six. Liability for breach of contract:

　　1, Party A terminates the contract before the completion of the first draft of the design work. The prepaid expenses have no right to request the return. If a party terminates the contract after the completion of the first draft of Party B's work, it shall pay the full design fee.

　　2. If Party B terminates the contract without proper reasons, the fees charged shall be returned to Party A.

　　Seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. If either party fails to negotiate, any Party A and B can submit it to the Beijing Arbitration Commission for arbitration.

　　Eight, the contract is effective from the date of signature by Gai Zhang and both parties. The contract is two copies in one form. Each party has one contract signed by the other party (Gai Zhang), which has the same legal effect.

　　Nine. If there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. The contents of the supplement and modification are equally valid to this contract.

　　Party A: Party B:

　　(signature seal) (signature seal)

　　Date: Date:

　　中文版

　　地址：

　　电话：

　　乙方：地址：

　　电话：

　　依据《中华人民共和国合同法》和有关法规的规定，乙方接受甲方的委托，就委托设计事项，双方经协商一致，签订本合同，信守执行：

　　一、委托事项：

　　二、付款方式：

　　1、甲方需在合同签订之时支付总费用的40% ，即____元(人民币)给乙方，乙方收到甲方的款项后开始设计。

　　2、乙方提供完整的设计稿，甲方确认后,应当即付清总费用的全部余款。

　　三、设计时间：

　　1、乙方需在__个工作日内提供比较完整的设计稿。

　　2、乙方需在_____年__月__日完成甲方公司委托的设计工作 (由甲方原因耽误的时间，完稿时间应顺延)。

　　四、双方的责任与义务：

　　1、乙方应按甲方要求按质按量按时完成相关设计工作。

　　2、甲方有责任全力配合乙方开展本合同所规定的工作，并根据乙方需要提供相关资料。由于甲方提供所需资料延误时间造成的后果，由甲方承担。

　　3、甲方应在设计开始前提供完整的设计资料，由于甲方提供资料不完整、内容改动而造成的设

　　计结构改动，甲方须另行支付相应的设计改动费用。

　　4、乙方收到甲方的完整设计资料后进行部分小样设计以方便甲方确定风格，风格确定后乙方开始进行初稿设计。

　　5、甲方有权对乙方所设计的作品提出修改意见，初稿甲方可提出一次结构上的修改，初稿确定后的.结构修改，甲方须另行支付相应费用。

　　6、因甲方修改，延误时间造成的后果，由甲方承担。

　　7、由于后期制作造成的损失由甲方独自承担，由于制作物设计出现问题造成的损失由乙方承担。因版权、文责所引发的法律责任，经济纠纷由甲方承担。

　　8、设计项目期间乙方挂靠于甲方品牌之中，不得以乙方身份单独与客户签订任何形式的合作协议。

　　五、知识产权约定：

　　1、乙方对设计完成的作品享有著作权。甲方将委托设计的所有费用结算完毕后，乙方可将作品著作权转让给甲方。

　　2、甲方在未付清所有委托设计费用之前，乙方设计的作品著作权归乙方，甲方对该作品不享有任何权利。

　　3、甲方在余款未付清之前擅自使用或者修改使用乙方设计的作品而导致的侵权，乙方有权追究其法律责任。

　　六、违约责任：

　　1、甲方在设计作品初稿完成前终止合同，其预付的费用无权要求退回；甲方在乙方作品初稿完成后终止合同的，应当支付全额的设计费用。

　　2、乙方如无正当理由提前终止合同，所收取的费用应当全部退回给甲方。

　　七、甲乙双方如因履行本合同发生纠纷，应当友好协商解决，协商不成的，甲乙双方任何一方均可向北京仲裁委员会提请仲裁解决。

　　八、本合同自甲乙双方签字盖章之日起生效，本合同一式两份，双方各持对方签字（盖章）合同一份，具有同等的法律效力。

　　九、本合同如有未尽事宜，由甲乙双方共同讨论补充或修改。补充和修改的内容与本合同具有同等效力。

　　甲方：乙方：

　　（签字盖章）（签字盖章）

　　日期：日期：

英文合同篇3

　　担保协议Guarantee Agreement 担保合同，（适用于银行担保项下）(Applicable to Bank Guarantee)

　　1.作为委托人的（以下称“委托人”）和

　　2.作为保证人的XX银行股份有限公司（以下称“保证人” ）签署。

　　This Guarantee Agreement (hereinafter referred to as the

　　“Agreement”) is made and entered into

　　as of (M/D/Y) between as the Client (hereinafter referred to as the

　　"Client") and Branch, China XXXX Bank as the Guarantor (hereinafter referred to as the“Guarantor”).

　　□本协议构成委托人与保证人签订的编号为年字第号的《授信协议》

　　（下称《授信协议》）的组成部分（本条适用的，在□中打“√”）。

　　The Agreement constitutes an integral part of the Credit Extension Agreement [20 ] No.

　　(hereinafter referred to as the “Credit Extension Agreement”) between the Client and the

　　Guarantor (if this paragraph applies, please click “√” in □).

　　鉴于：Whereas

　　1.委托人或被担保人（以下简称被担保人）与于年月日签署了总金额为币的编号为的关于的合同/ 标书（以下简称“合同”），或委托人

　　或被担保人参加了招标书编号为关于项目的投标（以下简称“投标”）；

　　1. The Client or the Guaranteed (hereinafter referred to as the “Guaranteed”)

　　signed No.Contract on/ Bid Document totaling (Currency) (hereinafter referred to as the “Contract”) withon (M/D/Y), or the

　　Client or the Guaranteed participated in the tender forProject with Bid

　　Document No. (hereinafter referred to as the “Bid”);

　　2.委托人申请保证人为委托人或被担保人开立上述合同或投标项下以

　　为受益人（以下称“受益人”），金额币，编号为的保函/备用信用证（下称“保函”）。

　　2. The Client applies to the Guarantor to open No. Letter of Guarantee/Stand-by LC

　　(hereinafter referred to as the “Letter of Guarantee”) with an amount of(Currency)

　　under the above Contract or Bid for the Client or the Guaranteed with as the Beneficiary (hereinafter referred to as the “Beneficiary”).

　　保证人同意应委托人申请按如下条件为委托人或被担保人向受益人开具上述保函：

　　The Guarantor agrees to issue the above letter of guarantee in favor of the beneficiary for the Client or the Guaranteed upon request of the Client on the following terms and conditions:

　　第1条在保证人开立保函之前，委托人应根据保证人的要求：

　　Article 1 Before the Guarantor issues the letter of guarantee, the Client shall upon request of the Guarantor:

　　1.1 向保证人提供下列保障（以下项目根据实际情况打“√”选择）：

　　1.1 Provide the Guarantor with the following security (please click “√” according to facts):

　　□1.1.1 在保证人处开立保证金账户（保证金账号为以保证金存入时甲方系统自动生成的帐号为准），存入金额为币的保证金，作为委托人履行本协议项下各项义务的质押担保，以备受益人索赔时偿付；和/或

　　□1.1.1 Open a guarantee fund account (A/C is generated automatically by Party A’s system when the guarantee fund is deposited) with the Guarantor, and deposit a guarantee fund of (Currency)as a pledge guarantee for the Client to perform each obligation under the

　　Agreement, and indemnify the Beneficiary at the time of claim; and/or

　　□1.1.2经保证人认可的企业法人、其他组织或自然人向保证人签发以保证人为受益人的不可撤销反担保书；和/或

　　□1.1.2 Have any corporation, or other organization or natural person recognized by the Guarantor issue the Guarantor with an irrevocable letter of counter guarantee in favor of the Guarantor; and/or

　　□1.1.3以保证人接受的抵押物或质物抵(质)押给保证人，以作为偿付担保。双方另订抵（质）押合同。（做删除标记）

　　本合同为《授信协议》项下具体合同的`，本条款不适用，本合同项下债务自动纳入与保证人签署了最高额抵/质押合同或向保证人出具了最高额不可撤销担保书的担保人的担保范围。If the Contract is a particular contract under the Credit Extension Agreement, this Article will be inapplicable, and the obligations under the Contract will be automatically included into the scope of undertaking by the undertaker signing a maximum mortgage/pledge contract with the guarantor or issuing the guarantor with a maximum irrevocable letter of undertaking.

　　1.2应保证人要求向保证人提供下列文件的正本或经委托人法定代表人签字并加盖公章证实为真实和完整的副本；

　　1.2 Upon request of the guarantor, provide the Guarantor with the original copies of the following documents or the duplicate copies signed by the legal representative of the Client and stamped with the official seal for proof of authenticity and integrity;

　　1.2.1委托人及/或被担保人的营业执照；

　　1.2.1 The business license of the Client and/or the Guaranteed;

　　1.2.2委托及/或被担保人的公司章程；

　　1.2.2 The articles of association of the Client and/or the Guaranteed;

　　1.2.3委托人全体现任董事名单及签字样本；

　　1.2.3 The name list and the specimen signature of all the current directors of the Client;

　　1.2.4同意委托人签署并执行本协议的委托人的董事会决议；

　　1.2.4 The resolution of the board of directors of the Client approving the Client to sign and execute the Agreement;

　　1.2.5委托人或被担保人与受益人签署的合同；或受益人的招标文件，投标人的投标文件；（做删除标记）

　　1.2.6委托人的上年度财务报表及审计报告书，以及申请前一个月的财务数据；

　　1.2.6 The Client’s financial statements and auditor’s report for the last year, and financial data for the month before the application;

　　1.2.7抵押物或质物的权属证件（若有抵押物或质物时）；（做删除标记）

　　1.2.8保证人要求的其他资料。

　　1.2.8 Other materials as requested by the Guarantor.

　　上述手续或材料以保证人实际要求的为准，并且为保证人应享有的权利而非义务，有关手续或材料是否完全齐备对本协议效力不构成影响。

　　The provision of the above formalities or materials shall be based upon the actual request of the Guarantor, which is a right entitled to but not a duty assumed by the Guarantor, and their completeness and fullness will not affect the legal force of the Agreement.

　　华译网翻译公司提供专业担保合同翻译服务。Shanghai Chinese consecutive interpretation service

　　华译网翻译公司提供专业同声传译服务。

　　第2条委托人在此向保证人声明、承诺和保证如下：

　　Article 2 The Client hereby makes a declaration, commitment and warrant to the Guarantor as follows:

　　2.1委托人为依照中华人民共和国法律正式成立及有效存在的商事主体，有充分的民事行为能力签订和履行本协议；

　　2.1 The Client is a commercial subject legally incorporated and validly in existence under the laws of the P. R. of China, and has full civil capacity to sign and perform the Agreement;

　　2.2委托人有合法的资格签署及履行本协议，签订和履行本合同已获得董事会或任何其他有权机构的充分授权；

　　2.2 The Client is eligible to sign and perform the Agreement, and has obtained the full authorization of the Board of Directors or any other competent authorities to sign and perform the Contract;

　　2.3 委托人或被担保人有合法资格与受益人签署合同，有足够的能力履行与受益人签署的合同；委托人保证委托人或被担保人履行与受益人签署的合同，并有义务及时向保证人通报履约情况及出现的问题；

　　2.3 The Client or the Guaranteed is eligible to sign the Contract with the Beneficiary, and has full capacity to perform the Contract signed with the Beneficiary; and the Client undertakes that the Client or the Guaranteed shall perform the Contract signed with the Beneficiary, and has duty to inform the Guarantor about the performance of contract and any issue arisen in due course;

　　2.4 委托人接受和认可保证人向受益人开立的保函的内容；

　　2.4 The Client accepts and acknowledges the contents of the letter of guarantee issued by the Guarantor to the Beneficiary;

　　2.5 委托人保证不使保证人因为开具保函而蒙受任何损害和损失；

　　2.5 The Client undertakes to protect the Guarantor from any damage or loss as a result of issuing the letter of guarantee;

　　2.6 委托人无条件地同意保证人按有关法律规定及/或在无其他约定的情况下按办理保函项下的一切事宜，并承担由此产生的责任；

　　2.6 The Client unconditionally agrees the Guarantor shall handle any matters under the letter of guarantee according to the relevant provisions of the laws except otherwise stipulated, and assume any liability arisen therefrom;

　　2.7委托人保证当受益人向保证人索赔时，委托人无条件承担第一位付款责任；

　　2.7 The Client undertakes that where the Beneficiary claims against the Guarantor, the Client shall unconditionally assume the primary liability for payment;

　　2.8委托人保证保函项下的项目符合国家有关法律法规的规定，由于项目本身而产生的一切经济和法律责任由委托人承担，与保证人无任何关联；

　　2.8 The Client undertakes that the project under the letter of guarantee conforms to the provisions

　　of the laws and regulations of the state, and any economic and legal liability arisen from the project itself shall be only borne by the Client, but have no relationship with the Guarantor;

　　2.9委托人同意按本协议规定，按期足额支付上述保函项下的依照保证人要求应付的各项费用；

　　2.9 The Client agrees to duly pay in full any expenses payable under the above letter of guarantee upon request of the Guarantor according to the provisions of the Agreement;

　　2.10 委托人同意保证人仅有义务审核保函项下受益人提交的索赔文件、单据或证明（以下统称“索赔文件”）的表面真实性，而不对索赔文件所述事实的真实性负任何责任；

　　2.10 The Client agrees that the Guarantor only has duty to examine the apparent authenticity of the claim documents, vouchers or certificates (hereinafter uniformly referred to as the “claim documents”) submitted by the Beneficiary under the letter of guarantee, but assume no liability for the authenticity of the facts stated in the claim

　　documents;

　　2.11委托人同意当因汇率波动或可能发生波动或保函修改等原因导致保证金账户资金不足时，将按保证人的要求不时存入足额资金，该资金自存入保证金账户之日起视为特定化并移交保证人占有，作为委托人履行本协议项下各项义务的质押担保；

　　2.11 The Client agrees to deposit adequate fund from time to time upon request of the Guarantor where the guarantee fund account falls short due to any movement or would-be movement of exchange rates or any amendment to the letter of guarantee, and such fund shall be deemed as designated and handed over to the occupancy of the Guarantor as of the date when it is deposited into the guarantee fund account as the pledge guarantee for the Client to perform each obligation under the Agreement;

　　2.12 委托人同意在办理保函业务时，如邮电、电讯传递过程中发生的任何延误、遗失、残缺或其他差错，保证人无须承担责任；

　　2.12 The Client agrees that the Guarantor shall assume no liability for any delay, loss, defect or other error incurred in the process of posts and telecommunications transmission at the time of handling the guarantee business;

　　2.13 委托人保证按季向保证人报送贷后检查所需财务数据及与保函业务相关的资料。

　　2.13 The Client undertakes to submit the Guarantor with any financial data required for post-loan examination and any materials related to the guarantee business quarterly.

英文合同篇4

　　合同编号：_________________

　　contract no：_______________

　　签订日期：_________________

　　date：______________________

　　签订地点：_________________

　　signed at ： _______________

　　电话：____________________

　　tel： ______________________

　　传真：____________________

　　fax：_______________________

　　电报：____________________

　　cable： ____________________

　　电传：____________________

　　telex： ____________________

　　电话：____________________

　　tel： ______________________

　　传真：____________________

　　fax：_______________________

　　电报：_____________________

　　cable： ____________________

　　电传：_____________________

　　telex： ____________________

　　经买双方确认根据下列条款订立该合同：

　　the undersigned sellers and buyers have confirmed this contract in accordance with the terms and conditions stipulated below ：

　　1. 货号

　　art no. 名称及规格

　　descriptions 单位

　　unit 数量

　　quantity 单价

　　unit price 金额

　　amount

　　合计：_______________

　　totally：____________

　　总值（大写）_______

　　total value：（in words）

　　允许溢短___%

　　____% more or less in quantity and value allowed.

　　2.成交价格术语：□ fob □ cfr □ cif □ ddu □

　　terms： ________________

　　3.包装：______________

　　packing： ______________

　　4.装运码头：__________

　　shipping marks： _______

　　5.运输起讫：由______经______到 ________

　　shipment________from_________to ________

　　6.转运：□ 允许 □ 不允许；分批装运：□ 允许 □ 不允许

　　tran shipment： □ allowed □ not allowed

　　partial shipments： □allowed □ not allowed

　　7.装运期：___________

　　shipment date： _______

　　8.保险：由____按发票金额110%投保____险，另加保____险至____为止。

　　insurance ： to be covered by the for 110% of the invoice value covering additional form ____to________

　　9.付款条件：

　　terms of payment：

　　买方不迟于_____年_____月_____日前将100%的货款用即期汇票/电汇送抵卖方。

　　the buyers shall pay 100% of the sales proceeds through sight（demand）draft/by t/t remittance to the sellers not later than

　　买方须于_____年_____月_____日前通过银行开出以卖方为受益人的不可撤销____天期信用证，并注明在上述装运日期后天在中国议讨有效，信用证须注明合同编号。

　　the buyers shall issue an irrevocable l/c at sight through in favour of the sellers prior to indicating l/c shall be valid in china through negotiation within day after the shipment effected ， the l/c must mention the contract number.

　　付款交单：买方应对卖方开具的以买方为付款人的见票后____天付款跟单汇票，付款时交单。

　　documents against payment：（d/p）

　　the buyers shall duly make the payment against documentary draft made out to the buyers at sight by the sellers.□承兑交单：买方应对卖方开具的以买方为付款人的见票后_____天承兑跟单汇票，承兑时交单。

　　documents against acceptance（d/a）

　　the buyers shall duly accept the documentary draft made out to the buyers at days by the sells.

　　10.单据：卖给方应将下列单据提交银行议付/托收。

　　documents require：the sellers shall present the following documents required for negotiation/collection to the banks.

　　整套正本清洁提单。

　　full set of clean on board ocean bills of lading.

　　商业发票一式____份。

　　signed commercial invoice in___copies.

　　装箱单或重量单一式_____份。

　　packing list/weight memo in copies.

　　由_____签发的质量与数量证明书一式______份。

　　certificate of quantity and quality in copies issued by ______

　　保险单一式______份。

　　insurance policy in copies.

　　由____签发的产地证一式____份。

　　certificate of origin in copies issued by __________

　　11.装运通知：一俟装运完毕，卖方应即电告买方合同号、品名、已装载数量，发票总金额，毛重，运输工具名称及启运日期等。 shipping advice ： the sellers shall immediately ， upon the completion of the loading of the goods ， advise the buyers of the contract no ， names of commodity ， loaded quantity ， invoice values ， gross weight ， names of vessel and shipment date by tlx/fax.

　　12.检验与索赔：

　　inspection and claims：

　　①卖方在发货前由检验机构对货物的品质、规格和数量进行检验，并出具检验证明书。

　　the buyers shall have the qualities ， specifications ， quantities of the goods carefully inspected by the inspection authority ， which shall issue inspection certificate before shipment.

　　②货物到达目的的口岸后，买方可委托当地的商品检验机构对货物进行复检。如果发现货物有损坏、残缺或规格、数量与合同规定不符，买方须于货到目的口岸的天内凭检验机构出具的检验证明书向卖方索赔。

　　the buyers have right to have the goods inspected by the local commodity inspection authority after the arrival of the goods at the port of destination. if the goods are found damaged / short / their specifications and quantities not in compliance with that specified in the contract， the buyers shall lodge claims against the sellers based on the inspection certificate issued by the commodity inspection authority within days after the goods arrival at the destination.

　　③如买方提供索赔，凡属品质异议须于货到目的`的口岸之日起天提出；凡属数量异议须于货到目的口岸之日起天提出。对所装货物所提任何异议应由保险公司、运输公司或邮递机构负责的，卖方不负任何责任。

　　the claims ， if any regarding to the quality of the goods shall be lodged within days after arrival of the goods at the destination ， if any regarding to the quantities of the goods ， shall be lodged within days after arrival of the goods at the destination . the sellers shall not take any responsibility if any claims concerning the shipping goods is up to the responsibility of insurance company / transportation company /post office.

　　13.人力不可抗拒：如因人力不可抗拒的原因造成该合同全部或部分不能履约，卖方概不负责，但卖方应将上述发生的情况及时通知买方。 force majeure ： the sellers shall not hold any responsibility for partial or total non-performance of this contract due to force majeure . but the sellers shall advise the buyers on times of such occurrence.

　　14.争议之解决方式：

　　disputes settlement ：任何因该合同而发生或与该合同有关的争议，应提交中国国际经济贸易仲裁委员会，按该会的仲裁规则进行仲裁。仲裁地点在中国深圳。仲裁裁决是终局的，对双方均有约束力。

　　all disputes arising out of the contract or in connection with the contract ， shall be submitted to the china international economic and trade arbitration commission for arbitration in accordance with its rules of arbitration in shenzhen ， china . the arbitral award is final and binding upon both parties.

　　15.法律适用

　　law application ：

　　该合同之签订地、或发生争议时货物所在地在中华人民共和国境内或被诉人为中国法人的，适用中华人民共和国法律，除此规定外，适用《联合国国际货物销售公约》。

　　it will be governed by the law of the people‘s republic of china under the circumstances that the contract is singed or the goods while the disputes arising are in the people’s republic of china or the deffendant is chinese legal person ， otherwise it is governed by united nations convention on contract for the international sale of goods .

　　该合同使用的fob、cfr、cif、ddu 术语系根据国际商会《incoterms 1990》

　　16.文字：该合同中、英两种文字具有同等法律效力，在文字解释上，若有异议，以中文解释为准。

　　versions ： this contract is made out in both chinese and english of which version is equally effective .conflicts between these two language arising therefrom . if any ， shall be subject to chinese version .

　　17.附加条款（该合同上述条款与本附加条款有抵触时，以本附加条款为准）

　　additional clauses ：（conflicts between contract clause here above and this additional clause ， if any ， it is subject to this additional clause）

　　18.该合同共_____份，自双方代表签字（盖章）之日起生效。

　　this contract is in copies ， effective since being signed / sealed by both parties： ______

　　卖方代表人：________________________ 买方代表人：_______________________

　　representative of the sellers ：____ representative of the buyers ：____

　　签字：______________________________ 签字：_____________________________

　　authorized signature ：_____________ authorized signature ：____________

英文合同篇5

　　买方 The Buyer:

　　地址 Address

　　Tel: Fax:

　　卖方 The Seller:

　　地址： Address

　　Tel: Fax:

　　本合同由买卖双方订立，根据本合同规定的条款，买方同意购买，卖方同意出售下述商品：

　　This Contract is made by and between the Buyers and Sellers, whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned commodity according to the terms and conditions stipulated below:

　　(1) 货名及规格 Commodity & Specification

　　(2) 数量 Qty.

　　(3) 单价 Unit Price

　　(4) 总价Total Amount

　　(5) 原产公司：COUNTRY OF ORIGIN :

　　(6) 装运期限：TIME OF SHIPMENT:

　　(7) 装运口岸：PORT OF SHIPMENT：

　　(8) 到货目的地：DESTINATION：

　　(9) 保险： INSURANCE：

　　由卖方按合同金额110％投保一切险和战争险

　　All Risks and War Risk for 110% contract value to be covered by the Seller.

　　(10) 运输方式：TERM OF SHIPMENT: 空运 By air

　　(11) 包装：PACKING：

　　须用坚固的新木箱包装，适合长途空运/陆运，防湿、防潮、防震、防锈、耐粗暴搬运。由于包装不良所发生的损失，由于采用不充分或不妥善的防护措施而造成的任何锈损、破损，卖方应负担由此而产生的一切费用和损失。包装箱内应包含一整套服务操作手册。卖方使用的木质包装应经薰蒸处理，并在木质包装表面标上清晰的IPPC标识。

　　To be packed in new strong wooden case(s) suitable for long distance air/land transportation and well protected from dampness, moisture, shock, rust and rough handling. The Sellers shall be liable for any damage to the goods on account of improper packing and for any rust damage and break damage attributable to inadequate or improper protective measures taken by the Sellers, and in such case or cases any and all losses and / or expenses incurred in consequence thereof shall be borne by the Sellers. One full set of service and operation manuals concerned shall be enclosed in the case(s). The wood packaging the Seller used shall be fumigated and marked with “IPPC” on the surface of wood packaging.

　　(12) 唛头：SHIPPING MARK:

　　卖方应在每件包装上，用不褪色油墨清楚地标刷件号、尺码、毛重、净重、“此端向上”、“小心轻放”、“切勿受潮”等字样，并刷有下列唛头:

　　On the surface of each package, the package number, measurements, gross weight, net weight, the lifting positions, such cautions as “THIS SIDE UP”, “HANDLE WITH CARE”,“KEEP AWAY FROM MOISTURE” and the following shipping mark:

　　(13) 付款条件：TERMS OF PAYMENT：

　　100%的合同金额通过电汇支付。100% contract value by T/T.

　　买方在合同生效后两周内支付合同金额的.100%货款

　　The Buyer shall pay 100% advance payment to the Seller within two week after contract effected.

　　(14) 单据：Documents,

　　1. 正本空运单（收货人联），标明“运费已付”及唛头，买方为收货人及通知方。

　　Original Airway Bill (copy for Consignee) marked “freight prepaid” and shipping mark, consign to and notify the Buyer.

　　2. 涵盖100%合同金额的商业发票三正三副，注明合同号、唛头。

　　Commercial invoice covering 100% of contract amount in 3 originals and 3 copies, indicating contract number, shipping mark.

　　3. 装箱单三正三副，注明毛、净重、尺码和所装货物的包装形式及数量。

　　Detailed Packing List in 3 originals and 3 copies indicating both gross and net weights, measurements and packing condition and quantity of each item packed.

　　4. 卖方出具的质量及数量证书正本三份。

　　Certificate of quality and quantity issued by seller in 3 originals.

　　5. 卖方出具的原产地证书一正一副。

　　Certificate of origin in 1 original and 1 copy issued by Seller.

　　6. 货物装运后24小时内卖方发给买方装运通知传真复印件一份。

　　Copy of fax from seller to the buyer advising the particulars of shipment within 24 hours after shipment is made.

　　7. 保险单或保险证明一正一副，按照合同金额110%投保一切险及战争险。

　　Insurance Policy or Certificate for 110% contract value, covering All Risks and War Risk in 1 original and 1 copy.

　　8. 卖方声明外包装表面标有IPPC标识证书正本一份, 或卖方出具的非木质包装证明正本

　　Seller’s Certificate in 1 original certifying IPPC has been marked on surface of the wooden cases / seller’s Certificate certifying no wood package is used in the shipment.

　　(15) 装运通知：SHIPPING ADVICE：

　　The Sellers shall fax to the Buyer the Readiness Notification one week before the goods to be shipped.

　　卖方在发货前一周物向买方传真货物备妥通知。

　　The Sellers shall, immediately upon the completion of the loading of the goods in 24 hours, send the Buyers Air Waybill, Invoice and Packing list by fax.

　　装运通知：卖方应在货物装运完毕后24小时内用传真将空运单、发票和装箱单发给买方。

　　如卖方未按时向买方通知上述装运情况所导致损失由卖方承担。

　　Losses shall be borne by the Sellers in case the Sellers don’t inform the Buyers of the above shipping status on time.

　　(16) 质量保证：GUARANTEE OF QUALITY:

　　卖方保证订货系用最上等的材料和头等工艺制成，全新的，未曾使用过的, 并完全符合本合同规定的质量、规格和性能。卖方并保证本合同订货在正确安装、正常使用和维修的情况下，自安装之日起十二个月或货物装运之日起十五个月内运转良好，以先到期者为准。由于人为造成的、易损易磨件除外。

　　The Sellers shall guarantee that for a period of 12 months calculated from the date of installation or 15 months starting from the date of shipment, whichever is the earlier. Faults due to mal-operation as well as wear and tear parts are excluded.

　　(17) 迟交货及罚款：LATE DELIVERY AND PENALTY

　　除合同第16条人力不可抗拒事故外，如卖方不能按合同规定的时间交货，买方应同意卖方支付罚款的条件下延期交货。罚款可由议付银行在议付货款时扣除，罚款率按每7天收0.5%，不足7天时以7天计算。但罚款不得超过迟交货物总价的5%。如卖方延期交货超过合同规定10周时，买方有权撤消合同，此时，卖方仍应不迟延地按上述规定向买方支付罚款。

　　买方有权对因此遭受的其它损失向卖方提出索赔。

　　Should the Sellers fail to make delivery on time as stipulated in the Contract, with the exception of Force Major causes specified in Clause 16 of this Contract, the Buyers shall agree to postpone the delivery on condition that the Sellers agree to pay a penalty which shall be deducted by the paying bank from the payment under negotiation. The penalty, however, shall not exceed 5% of the total value of the goods involved in the late delivery, the rate of penalty is charged at 0.5% for every seven days, odd days less than seven days should be counted as seven days. In case the Sellers fail to make delivery ten weeks later than the time of shipment stipulated in the Contract, the Buyers shall have the right to cancel the contract and the Sellers, in spite of the cancellation, shall still pay the aforesaid penalty to the Buyers without delay. The buyer shall have the right to lodge a claim against the seller for the losses sustained if any.

　　(18) 检验和索赔: INSPECTION AND CLAIMS:

　　如发现货物的品质、数量/重量与本合同不符, 买方有权在货物到达目的地后60天内根据中华人民共和国出入境检验检疫局出具的商检证书向卖方提出索赔。由承运人和保险公司负责的赔偿除外。

　　If the quality and/or quantity/weight be found not in conformity with the present contract, the Buyer shall be entitled to lodge claims with the Seller on the basis of the Certificate issued by China Exit and Entrance Inspection and Quarantine Bureau within 60 days after the goods arrival in the destination. With the exception, however, of those claims for which the carrier and/or insurance company are to be held responsible.

　　(19) 人力不可抗拒事故：FORCE MAJEURE：

　　由于人力不可抗拒事故，而卖方交货延迟或不能交货时，责任不在卖方，但卖方应立即将事故通知买方，并于事故发生后十四天内将事故发生地政府主管机关出给的事故证明书用空邮寄交买方为证，并取得买方认可。在上述情况下，卖方仍负有采取一切必要措施从速交货的责任。如果事故持续超过十个星期买方有权撤销本合同。

　　The Sellers shall not be held responsible for any delay in delivery or non-delivery of the goods duo to Force Majeure. However, the Sellers shall advise the Buyers immediately of such occurrence and

　　within fourteen days thereafter, shall send by airmail to the buyers for their acceptance a certificate

　　issued by the competent government authorities of the place where accident occurs as evidence

　　thereof. Under such circumstances the Sellers, however, are still under the obligation to take all

　　necessary measures to hasten the delivery of the goods. In case the accident lasts for more than ten

　　weeks, the Buyers shall have the right to cancel this Contract.

　　(20) 仲裁：ARBITRATION:

　　凡因执行本合同所发生的或与本合同有关的一切争议，应由双方通过友好协商予以解决，应提交中国国际经济贸易仲裁委员会根据中国国际经济贸易仲裁规则进行仲裁，仲裁裁决是终局的，对双方都有约束力。

　　All disputes arising from the execution of or in connection with this contract, shall be settled amicably through friendly negotiation. In case no settlement can be reached through negotiation the case shall then be submitted to China International Economic and Trade Arbitration Commission in Shanghai arbitration in accordance with The Rules of Arbitration of China International Economic & Trade Commission. The award rendered by the said commission shall be final and binding upon both parties.

　　（21）通知 NOTICE

　　所有通知用中/英文写成，按照合同所列地址用传真/快递送达给各方。如果地址有变更，一方应在变更后3日内书面通知另一方。

　　All notice shall be written in Chinese or English and served to both parties by fax/courier according to the addresses shown in this contract. If any changes of the addresses occur, one party shall inform the other party of the change of address within 3 days after the change.

　　(22) 其他 MISCELLANEOUS

　　本合同一式二份，买方执一份，卖方执一份，由双方代表正式签字盖章生效。

　　The present contract is in three copies of the same form, the buyer holds two; the seller holds one. The contract is signed by the authorized representative of both parties and shall become effective upon the formal and mutual signing and stamping of the contract.

　　买方: The Buyer: 卖方：The Seller:

英文合同篇6

　　合同号：_________

　　no：_________

　　日期：_________

　　date：_________

　　为在平等互利的基础上发展贸易，有关方按下列条件签订本协议：

　　this agreement is entered into between the parties concerned on the basis of equality and mutual benefit to develop bussiness on terms and conditions mutually agreed upon as follows:

　　1．订约人

　　contracting parties

　　供货人（以下称甲方）：_________

　　supplier（hereinafter called “party a”）:_________

　　销售代理人（以下称乙方）：_________

　　agent（hereinafter called “party b”）:_________

　　甲方委托乙方为销售代理人，推销下列商品。

　　party a hereby appoint party b to act as his selling agent to sell the commodity mentioned below.

　　2．商品名称及数量或金额

　　commodity and quantity or amount

　　双方约定，乙方在协议有效期内，销售不少于_________的商品。

　　it is mutually agreed that party b shall undertake to sell not less than _________ of the aforesaid commodity in the duration of this agreement。

　　3．经销地区

　　territory

　　只限在_________。

　　in _________ only.

　　4．订单的确认

　　confirmation of orders

　　本协议所规定商品的数量、价格及装运条件等，应在每笔交易中确认，其细目应在双方签订的销售协议书中作出规定。

　　the quantities， prices and shipments of the commodities stated in this agreement shall be confirmed in each transaction， the particulars of which are to be specified in the sales confirmation signed by the two parties hereto.

　　5．付款

　　payment

　　订单确认之后，乙方须按照有关确认书所规定的时间开立以甲方为受益人的保兑的、不可撤销的即期信用证。乙方开出信用证后，应立即通知甲方，以便甲方准备交货。

　　after confirmation of the order， party b shall arrange to open a confirmed， irrevocable l/c available by draft at sight in favour of party a within the time stipulated in the relevant s/c. party b shall also notify party a immediately after l/c is opened so that party a can get prepared for delivery.

　　6．佣金

　　commission

　　在本协议期满时，若乙方完成了第二款所规定的数额，甲方应按装运货物所收到的发票累计总金额付给乙方_________％的'佣金。

　　upon the expiration of the agreement and party b's fullfilment of the total turnover mentioned in article 2， party a shall pay to party b _________% commission on the basis of the aggregate amount of the invoice value against the shipments effected.

　　7．市场情况报告

　　reports on market conditions

　　乙方每3个月向甲方提供一次有关当时市场情况和用户意见的详细报告。同时，乙方应随时向甲方提供其他供应商的类似商品样品及其价格、销售情况和广告资料。

　　party b shall forward once every three months to party a detailed reports on current market conditions and of consumers' comments. meanwhile， party b shall，from time to time， send to party a samples of similar commodities offered by other suppliers， together with their prices， sales information and advertising materials.

　　8．宣传广告费用

　　advertising & publicity expenses

　　在本协议有效期内，乙方在上述经销地区所作广告宣传的一切费用，由乙方自理。乙方须事先向甲方提供宣传广告的图案及文字说明，由甲方审阅同意。

　　party b shall bear all expenses for advertising and publicity within the aforementioned territory in the duration of this agreement and submit to party a all patterns and/or drawings and description for prior approval.

　　9．协议有效期

　　validity of agreement

　　本协议经双方签字后生效，有效期为_________天，自_________至_________。若一方希望延长本协议，则须在本协议期满前1个月书面通知另一方，经双方协商决定。

　　若协议一方未履行协议条款，另一方有权终止协议。

　　this agreement， after its being signed by the parties concerned， shall remain in force for _________ days from _________ to _________ if either party wishes to extend this agreement， he shall notice， in writing， the other party one month prior to its expiration. the matter shall be decided by the agreement and by consent of the parties hereto. should either party fail to implement the terms and conditions herein， the other party is entitled to terminate this agreement.

　　10．仲裁

　　arbitration

　　在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商达不成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会的决定是终局的，对双方均具有约束力。仲裁费用，除另有规定外，由败诉一方负担。

　　all disputes arising from the execution of this agreement shall be settled through friendly consultations. in case no settlement can be reached， the case in dispute shall then be submitted to the foreign trade arbitration commission of the china council for the promotion of international trade for arbitration in accordance with its provisional rules of procedure. the decision made by this commission shall be regarded as final and binding upon both parties. arbitration fees shall be borne by the losing party ，unless otherwise awarded.

　　11．其他条款

　　other terms & conditions

　　（1）甲方不得向经销地区其他买主供应本协议所规定的商品。如有询价，当转达给乙方洽办。若有买主希望从甲方直接订购，甲方可以供货，但甲方须将有关销售确认书副本寄给乙方，并按所达成交易的发票金额给予乙方_________％的佣金。

　　party a shall not supply the contracted commodity to any other buyer(s) in the above mentioned territory. direct enquiries， if any， will be referred to party b. however， should any other buyers wish to deal with party a directly， party a may do so. but party a shall send to party b a copy of sales confirmation and give party b _________% commission on the basis of the net invoice value of the transaction(s)concluded.

　　（2）若乙方在_________月内未能向甲方提供至少_________订货，甲方不承担本协议的义务。

　　should party b fail to pass on his orders to party a in a period of _________ months for a minimum of _________， party a shall not bind himself to this agreement.

　　（3）对双方政府间的贸易，甲方有权按其政府的授权进行有关的直接贸易，而不受本协议约束。乙方不得干涉此种直接贸易，也无权向甲方提出任何补偿或佣金要求。

　　for any business transacted between governments of both parties， party a may handle such direct dealings as authorized by party a's government without binding himself to this agreement. party b shall not interfere in such direct dealings nor shall party b bring forward any demand for compensation therefrom.

　　（4）本协议受签约双方所签订的销售确认条款的制约。

　　this agreement shall be subject to the terms and conditions in the sales confirmation signed by both parties hereto.

　　12．本协议于_________年_________月_________日在_________签订，正本两份，甲乙双方各执一份。

　　this agreement is signed on _________ at _________ and is in two originals；each party holds one.

　　甲方（签字）：_________ 乙方（签字）：_________

　　party a(signature):_________ party b(signature):_________

英文合同篇7

　　this agreement of lease is made on this 16th day of december XX by and between:-

　　mrs. ghazala waheed w/o abdul waheed, adult, r/o house no.***-*, dha, lahore cantt, (hereinafter to as the lessor of the one part).

　　and

　　mr.* ***,r/o china, refereed to as the lessee of the other part.(expression “lessor”

　　and “lessee” wherever the context so permit shall always mean and include their respective heirs, successors legal representative and assignees).

　　whereas the lessor is the lawful owner and in lawful possession of house no,***-*,dha,

　　lahore cantt, consisting of 4 bedrooms with bath, d/d,tv; lounge, kitchen, store, servant, quarter together with fixtures and fitting (hereinafter collectively called the demised premises).

　　and whereas the lessor has agreed the lease and the lessee has agreed to take on lease the demised premises on the terms and condition as given below:-

　　1. this agreement in only valid if lessee is renewed and extended for the lease period.

　　2. the lessor lets lessee takes the demissed premises for a period of 12 months

　　commencing from 15th january XX. the lease is renewable for a further period as may be mutually agreed in writing on expiry of the lease period

　　3. the rent of the demised premises shall be usd3,300/-(us dollars three thousand and three hundred only) per month

　　4. the lessor hereby acknowledges receipt of the sum of usd.19,800/-(us dollars nineteen thousand and eight hundred only) per month.

　　5. it is hereby agreed between the parties that the lessee shall pay the aforesaid monthly rent

　　usd. 3,300/-(us dollars three thousand and three hundred only) as the monthly rental advance by 20th of each calendar month for which if is due after completion of advance rent period ending on 15th july XX.

　　6. that the lessor hereby acknowledges receipt of the sum of rs.60,000/-(rupees sixty thousand only) from the lessee as fixed edposit security which shall be refunded to the lessee on giving back the vacant possession of the demised premises after deduction of damages/shortages outstanding bills for electricity, water, gas and telephone charges etc, against the demised premises.

　　the lessee herby convenants with lessor as following:

　　1. to pay to the lessor the rent hereby reserved in the manner before mentioned.

　　2. that the lessee shall not at any time during the terms, without the consent in writing of the lessor, pull down, damages or make any structure alterations to the demised premeses provided always, the lessee shall have go write install any fixtures and fittings excluding air-conditioners in the demised premeses, to detach and repossess the same subject to the restoration of the demised premeses to their original state at his cost (reasonable wear and tear excepted) on the expiry of this lease or any renewal hereof.

　　3. to use the demises premises for residen

　　tial purpose and would not be used for a commercial purpose the demises premise would not be used occupied by mr. ****

　　and family.

　　4. not to sublet the whole or any part of the premises.

　　5. to pay regularly the bills for electricity, gas, water and telephone charges in respect of the demised premises. a copy of all the paid utility bill be forwarded to the lessor every three month regularly. in case of disconnection of any facility due to non-payment, lessee will be responsible to get them restored and pay the same. all dues must be cleared before the expiry of the lease.

　　6. the lessee shall keep and maintain the said premises in good and tenantable conditions during the tenure of the lease.

　　the lessor hereby convenants with the lessee as following:-

　　1. to pay all existing and future rate, taxes assessments and other charges of a public nature whether impose by the municipality, government or any other authority in respect of demised premises.

　　2. not to erect or set up a building or structure on the demises premises nor to add to any existing building or structure during the period of lease or any renewal without the written consent of the lessee.

　　it is hereby declear and muturally agreed between the lessor and lessee ans follwing:=

　　1. the lessee and the lessor shall have the right and option to terminate this lease at any time only after the expiry of the lease period i.e., 24 months, provided they give one (1) month notice in advance to either of the parties.

　　2. the meter reading of various utilities are as given below:-

　　utility meter number today’s reading

　　a) elecricity ———————— ————————

　　b) gas ———————— ————————

　　c) telephone ———————— ————————

英文合同篇8

　　金苑服饰有限公司销售合同

　　Jinyuan Garments & Accessories Co., Ltd

　　SALES CONTRACT

　　合同编号：JYFS120602

　　CONTRACT NO. JYFS120602

　　日期：20xx年6月22日

　　DATEJune 22, 20xx

　　买方美国纽约第五大道服装大卖场

　　联系电话：+537 070 186 532传真：+537 070 186 532

　　BUYERThe United States 5th Avenue clothing hypermarket

　　TEL: +537 070 186 532 FAX: +537 070

　　卖方中国福建金苑服饰有限公司

　　联系电话：0595—7656300 传真：0595—7656300

　　SELLERChina Fujian Jinyuan GARMENTS & ACCESSORIES CO.,

　　LTD

　　TEL: 0595—7656300 FAX: 0595—7656300

　　双方同意按下列条款由买方购进卖方售出下列商品: The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as below :

　　(1) 货物名称及规格，包装及装运标志 | (2) 数量（件）| (3) 单价（美元） | (4) 总价（美元）

　　Name of Commodity, Specifications, QuantityUnit Price ($)Total Amount($)

　　Packing and Shipping Marks

　　金苑20xx新品衬衫，货号：A22105400024.00 96000.00

　　Jinyuan20xx New Shirt, Item No.A22105 4000 24.00 96000.00

　　金苑20xx新品衬衫，货号：H22103400024.70 98800.00

　　Jinyuan20xx New Shirt , Item No.h22103 4000 24.70 98800.00

　　金苑20xx新品衬衫，货号：A22111400021.30 85200.00

　　Jinyuan20xx New Shirt , Item NoA22111 400021.30 85200.00

　　金苑20xx新品休闲淑女裤， 600030.50 183000.00

　　货号：C22105

　　Jinyuan 20xx New Casual Lady pants 6000 30.50183000.00

　　Item No.:C22105

　　金苑20xx新品休闲七分裤， 600032.40 194400.00

　　Jinyuan20xx New Casual Cropped pants6000 32.40 194400.00

　　货号：C22108

　　Item No. C22108

　　规格

　　Specification

　　材料：50%—80%棉，20%—50%涤纶；Material: 50%-80% cotton 20%-50% dacron

　　尺寸：S—XL，每种款式各个尺寸配送 Size：S-XL, The distribution number of each style in all size,

　　namely each size distribute 1/4 of the total number

　　配送数量，即每个尺寸配送数量占每种

　　总数量的1/4；

　　颜色：每种产品所具有的颜色都配送相 Color:the color of each kind of product distribute the same quantity.namely distribution quantity=total number/the number of color

　　等数量，即配送数量=总件数/颜色总数；

　　包装：单件产品用透明塑料袋包装，每个Packing:A single product with a transparent plastic bag

　　纸箱装50件尺寸一致的产品，纸箱外部 50 pieces of products in each carton of the same size

　　由防水袋包裹，内置50克干燥剂一袋，Wrapped by waterproof bag, with a bag of 50 grams desiccant

　　纸箱规格为60*70*900（mm）；并配 Carton standard 60*70*900（mm）

　　送24000个金苑服饰购物袋。Distribute 24000 pieces of Jinyuan shipping bags.

　　装运标志：

　　Shipping mark 总计: Total No. (装运数量允许有2%的增减 Shipping Quantity Two Percent More or Less Allowed)

　　(5) 装运期限

　　Time of Shipment50DAYS AFTER THE SELLER RECEIVE

　　THE L/C.

　　(1) 装运口岸福建泉州新港

　　Port of shipment

　　(2) 目的口岸伊丽莎白港

　　Port of Destination

　　(3) 保险投保

　　Insurance

　　(4) 付款条件

　　Terms of Payment IRREVOCABLE L/C AT SIGHT

　　该信用证必须在 45天前开到卖方, 信用证的有效期应为装船期后15天, 在上述装运口岸

　　到期, 否则卖方有权取消本售货合约并保留因此而发生的'一切损失的索赔权 .

　　The covering Letter of Credit must reach the Sellers 45 Days Prior to the Shipment Date

　　and is to remain valid in above indicated Loading Ports 15 days after the date of shipment, failing

　　which the Sellers reserve the right to cancel this Sales Contract and to claim from the Buyers

　　compensation for losses resulting therefrom.

　　其他条款 OTHER TERMS :

　　（1）异议 : 品质异议须于货到目的口岸之日起30天内提出,数量异议须于货到目的口岸之日 ALL RISK AND WAR RISK COVERED BY BUYER

　　起15天内提出。但均须提供经卖方同意的公证行的检验证明. 如责任属于卖方者卖方于收到异议20天内答复买方并提出处理意见.

　　QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shou

　　ld be filed by the Buyers within 30 days after the arrival of the goods at port of destination, while for quantity discrepancy claim should be filed by the Buyers within 15 days after the arrival of the goods at port of destination. In all cases, claims must be accompanied by Survey Reports of Recognized Public Surveyors agreed to by the Sellers. Should the responsibility of the subject under claim be found to rest on part of the Sellers, the Sellers shall, within 20 days after receipt of the claim, send his reply to the Buyers together with suggestion for settlement..

　　（2）信用证内应明确规定卖方有权可多装或少装所注名的百分数，并按实际装运数量议付。（信用证之金额应较本售货合约的金额增加相应的百分数）

　　The Sellers reserve the option of shipping the indicated percentage more or less than the quantity hereby contracted, and the Letter of Credit shall be negotiated for the amount covering the value of quantity actually shipped. (The Buyers are requested to establish the L/C in accord with the indicated percentage over the total value of order as per this Sales Contract.)

　　（3）信用证内容须严格符合本售货合约的规定，否则修改信用证的费用由买方负担，卖方亦不负因修改信用证而延误装运的责任。并保留因此而发生的一切损失的索赔权。

　　The contents of the Letter of Credit shall be in strict accordance with stipulations of the Sales Contract; in case of any variation thereof necessitating amendment of the L/C, the Buyers shall bear the expenses for effecting the amendment. The sellers shall not be held responsible for possible delay of shipment resulting from awaiting the amendment of the L/C, and reserve the right to claim from the Buyers compensation for the losses resulting therefrom..

　　（4）除经约定保险归买方投保者外，由卖方向中国的保险公司投保。如买方须增加保险额或须加保其他险，可于装船前提出，经买方同意后代为投保，其费用由买方负担。

　　Except where the insurance is covered by the Buyers as arranged, insurance is to be covered by the Sellers with a Chinese insurance company. If insurance for additional amount and/or for other insurance terms is required by the Buyers, prior notice to this effect must reach the Sellers before shipment and is subject to the Sellers’ agreement, and the extra insurance premium shall be for the Buyers’ account..

　　（5）买方须将申请许可证副本（经有关银行副署）寄给卖方俟许可证批出后再即用传真通知

　　卖方，假如许可证被驳退，买方须征得卖方的同意方可重行申请许可证。

　　The Buyers are requested to send the Sellers authentic copy of the License-application (endorsed by the relative bank) filed by the Buyers and to advise the Sellers by fax immediately when the said License is obtained. Should the Buyers intend to file reapplication for License in cases of rejection of the original application, the Buyers shall contact the Sellers and obtain the latter’s consent before filing reapplication..

　　（6）商品检验：产地证明书或中国有关机构所签发的品质数量/重量检验证，作为品质数量/ 重

　　量的交货依据。

　　INSPECTION:The Certificate of Origin and/or the Inspection Certification ofQuality/Quantity/Weight issued by the relative institute shall be taken as the basis for the shipping Quality/Quantity/Weight..

　　（7）因人力不可抗拒事故，使卖方不能在本售货合约规定期限内交货或不能交货，卖方不负

　　责任，但是卖方必须立即以传真通知买方，如果买方提出要求，卖方应以挂号函向买方提供由中国国际贸易促进委员会或有关机构出具的证明，证明事故的存在。买方不能领到进口证不能被认为系属人力不可抗拒范围。

　　The Sellers shall not be held responsible if they owing to Force Majeure cause or causes fail to make

　　delivery within the time stipulated in this Sales contrast or cannot delivery the goods. However the Sellers shall inform immediately the Buyers by fax. . The Sellers shall delivery to the Buyers by registered letter, if it is requested by the Buyers, a certificate issued by the China council for the Promotion of International Trade or by any competent authority, certifying to the existence of the said cause or causes. Buyers’ failure to obtain the relative Import license is not to be treated as Force Majeure.

　　（8）仲裁：凡因执行本合约或有关本合约所发生的一切争执，双方应以友好方式协商解决，如果协商不能解决，应提交北京中国国际贸易促进委员会对外贸易仲裁委员会根据中国国际贸易促进委员会对外贸易仲裁委员会的仲裁程序暂行规则进行仲裁，仲裁裁决是终局的，对双方都有约束力。

　　ARBITRATION : All disputes arising in connection with the Sales Contract of the executionthereof shall be settled amicably by negotiation. In case no settlement can be reached, the case under dispute shall then be submitted for arbitration to the Foreign Trade Arbitration commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure of the Foreign Trade Arbitration commission of the China council for the Promotion of International Trade. The decision of the Commission shall be accepted as final and binding upon both parties.

　　买方：美国第五大道服装大卖场卖方：中国福建金苑服饰有限公司

　　THE BUYERS:The United States 5th Avenue clothing hypermarket

　　THE SELLERS: China Fujian Jinyuan Garments Co., Ltd.

　　买方代表签字：卖方代表签字：

　　Buyer representative signature: Seller representative signature:

英文合同篇9

　　合同 CONTRACT

　　日期：合同号码：

　　Date: Contract No.:

　　买方： (The Buyers) 卖方： (The Sellers)

　　兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：

　　This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:

　　(1) 商品名称:

　　Name of Commodity：

　　(2) 数量：

　　Quantity:

　　(3) 单价：

　　Unit price:

　　(4) 总值：

　　Total value:

　　(5) 包装：

　　Packing:

　　(6) 生产国别：

　　Country of Origin :

　　(7) 支付条款：

　　Terms of Payment:

　　(8) 保险：

　　Insurance:

　　(9) 装运期限：

　　Time of Shipment:

　　(10) 起运港：

　　Port of Lading:

　　(11) 目的港：

　　Port of Destination:

　　(12)索赔：

　　在货到目的'口岸45天内如发现货物品质，规格和数量与合同不符，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。

　　Claims:

　　Within 45 days after the arrival of the goods at the destination, should the quality, Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable.

　　The Buyers shall, have the right on the stren

　　gth of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers.

　　(13)不可抗力：

　　由于人力不可抗力的原由，发生在制造、装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任。在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽快发货。

　　Force Majeure:

　　The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after. The Sellers shall send by airmail to the Buyers for their acceptance certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods.

　　(14）仲裁：

　　凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。

　　Arbitration:

　　All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. In case no settlement can be reached, the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rule

　　s of Procedure promulgated by the said Arbitration Commission. The Arbitration committee shall be final and binding upon both parties. And the Arbitration fee shall be borne by the losing parties.

　　买方：卖方:

　　（授权签字）（授权签字）

英文合同篇10

　　Employer: ___________ construction co., LTD. (hereinafter referred to as party a)

　　Contractor: _______________________________(hereinafter referred to as party b)

　　In accordance with the contract law of the People's Republic of China, the construction law of the People's Republic of China and the interim provisions on the administration of labor contract administration of project projects. Party a decided to ________________ company alarm project subcontracting to party b department, to standardize the management, clear responsibility, agreed by both parties, this contract is made, to abide by.

　　1. The contents of labor construction projects contracted by party a to party b are as follows:

　　All bricks, stone masonry and plastering projects in the construction blueprint of the project; Rebar production and binding sub-projects; Template making and installation of sub-projects; Scaffolding works.

　　Ii. Term of this contract:

　　From the beginning of ___________ to _______ _______ _______.

　　Iii. Engineering quality standard:

　　The quality of all itemized projects is assured.

　　Iv. Payment and payment method of labor management fee:

　　1, turned over standard: the labor service project management fee RMB $ten thousand, paid by party b, party b can achieve according to the contract that the project department and construction quality, progress of the requirements of party a according to the management fee of _____ % back to party b as a reward.

　　Payment method: payment of service fee shall be paid in two installments, that is, 50% before the main body is finished and 50% before the decoration is completed.

　　V. responsibilities of party b.

　　1. Party b shall provide relevant documents and qualifications and cooperate with party b to handle relevant procedures.

　　To coordinate labor disputes and industrial accidents during construction.

　　Vi. Responsibilities of party b:

　　1, I am grateful to fully perform __________________ company and construction co., LTD. The project construction contract signed. And shall bear all the responsibilities and obligations of party b in the contract.

　　2. Ensure the quality, progress and safety of all sub-projects to meet the contract requirements signed by the project department and the construction party. If not, it will be punished by 50% of the management fee.

　　Vii. Matters not covered herein shall be negotiated by both parties, and the supplementary provisions may be signed by the parties hereto, which shall have the same legal effect as this contract.

　　Viii. This contract is made in six originals, with each party holding three copies. The contract shall be executed by both parties and shall be completed upon completion of the project.

　　Party a: _______________________ party b: ________________________

　　Party a's representative: __________________ party b's representative: __________________.

　　中文版

　　发包方：___________建筑施工有限责任公司(以下简称甲方)

　　承包方：_______________________________(以下简称乙方)

　　依照《中华人民共和国合同法》、《中华人民共和国建筑法》及公司《关于工程项目劳务承包管理暂行规定》。甲方决定将________________公司______________工程项目部的劳务分包给乙方，为规范管理，明确职责，经双方协商一致，特签订本合同，以资共同遵守。

　　一、甲方发包给乙方的劳务施工项目内容范围如下：

　　该工程项目施工蓝图中所有砖、石砌筑及抹灰分项工程;钢筋制作、绑扎分项工程;模板制作、安装分项工程;脚手架搭设作业。

　　二、本合同期限：

　　从______年_____月起至___________年_______月止。

　　三、工程质量标准：

　　所有分项工程质量确保优良